Warranties and Disclosures

Warranty Statement: All manufacturers products including fixtures, outlets, switches, controllers, panels, breakers, etc. will be honored per manufactures warranty offering not including labor to service, install or maintain various products. Skilled labor and craftsmanship is warrantied for 30 days after installation is complete and customer accepted as substantial completion.

General Service Agreement

THIS GENERAL SERVICE AGREEMENT (the “Agreement”) BETWEEN COMPANY RECEIVER’S NAME of COMPANY RECEIVER’S ADDRESS (the “Customer”)
– AND –
Bright Ideas Lighting Company (the “Contractor”).

BACKGROUND:

1. The Customer is of the opinion that the Contractor has the necessary qualifications, experience and abilities to provide services to the Customer.
2. The Contractor is agreeable to providing such services to the Customer on the terms and conditions set out in this Agreement.

IN CONSIDERATION OF the matters described above and of the mutual benefits and obligations set forth in this Agreement, the receipt and sufficiency of which consideration is hereby acknowledged, the Customer and the Contractor (individually the “Party” and collectively the “Parties” to this Agreement) agree as follows:

Services Provided

1. The Customer hereby agrees to engage the Contractor to provide the Customer with services (the “Services”) consisting of:
Scope of work outlined in quotation, scope of work or bid document
2. The Services will also include any other tasks which the Parties may agree on. The Contractor hereby agrees to provide such Services to the Customer.
Term of Agreement
3. The term of this Agreement (the “Term”) will begin on the date of this Agreement and will remain in full force and effect indefinitely until terminated as provided in this Agreement.
4. In the event that either Party wishes to terminate this Agreement, that Party will be required to provide 30 days notice to the other Party.
5. Except as otherwise provided in this Agreement, the obligations of the Contractor will end upon the termination of this Agreement or completion of the scope of work.
Performance
6. The Parties agree to do everything necessary to ensure that the terms of this Agreement take effect.

Currency

7. Except as otherwise provided in this Agreement, all monetary amounts referred to in this Agreement are in US Dollars.

Compensation

8. For the services rendered by the Contractor as required by this Agreement, the Customer will provide compensation (the “Compensation”) to the Contractor as follows:
• The Customer will pay the Contractor per project agreed. Each project has its own costs and the Contractor agrees to inform the Customer what are the costs involved when setting the quotation and the Customer agrees to pay the total amount when the project is delivered or in agreed phases.
9. The Compensation will be payable upon completion of the services or phases outlined in the scope of work.
10. The Contractor is responsible for paying any sub-contract work that may be required in relation to the work performed by the Contractor or by employees of the Contractor under this Agreement.
11. The above Compensation includes all applicable sales tax, and duties as required by law.

Provision of Extras

12. The Customer will not provide any resources, assistance or extras for use by the Contractor in providing the Services.

Reimbursement of Expenses

13. The Contractor will not be reimbursed for expenses incurred by the Contractor in connection with providing the Services of this Agreement.

Confidentiality

14. Confidential information (the “Confidential Information”) refers to any data or information relating to the business of the Customer which would reasonably be considered to be proprietary to the Customer including, but not limited to, accounting records, business processes, and client records and that is not generally known in the industry of the Customer and where the release of that Confidential Information could reasonably be expected to cause harm to the Customer.
15. The Contractor agrees that they will not disclose, divulge, reveal, report or use, for any purpose, any Confidential Information which the Contractor has obtained, except as authorized by the Customer. This obligation will survive indefinitely upon termination of this Agreement.
16. All written and oral information and material disclosed or provided by the Customer to the Contractor under this Agreement is Confidential Information regardless of whether it was provided before or after the date of this Agreement or how it was provided to the Contractor.

Return of Property

17. Upon the expiry or termination of this Agreement, the Contractor will return to the Customer any property, documentation, records, or Confidential Information which is the property of the Customer.

Capacity/Independent Contractor

18. In providing the Services under this Agreement it is expressly agreed that the Contractor is acting as an independent contractor and not as an employee. The Contractor and the Customer acknowledge that this Agreement does not create a partnership or joint venture between them, and is exclusively a contract for service.

Notice

19. All notices, requests, demands or other communications required or permitted by the terms of this Agreement will be given in writing and delivered to the Parties of this Agreement as follows:
a. COMPANY RECEIVER’S ADDRESS Email:
b. Bright Ideas Lighting Company service@brightideaslightco.com
or to such other address as any Party may from time to time notify the other.

Dispute Resolution

22. In the event a dispute arises out of or in connection with this Agreement, the Parties will attempt to resolve the dispute through friendly consultation.
23. If the dispute is not resolved within a reasonable period then any or all outstanding issues may be submitted to mediation in accordance with any statutory rules of mediation. If mediation is unavailable or is not successful in resolving the entire dispute, any outstanding issues will be submitted to final and binding arbitration in accordance with the laws of the State of Idaho. The arbitrator’s award will be final, and judgment may be entered upon it by any court having jurisdiction within the State of Idaho.

Modification of Agreement

24. Any amendment or modification of this Agreement or additional obligation assumed by either Party in connection with this Agreement will only be binding if evidenced in writing signed by each Party or an authorized representative of each Party.

Time of the Essence

25. Time is of the essence in this Agreement. No extension or variation of this Agreement will operate as a waiver of this provision.

Assignment

26. The Contractor will not voluntarily or by operation of law assign or otherwise transfer its obligations under this Agreement without the prior written consent of the Customer.
Entire Agreement
27. It is agreed that there is no representation, warranty, collateral agreement or condition affecting this Agreement except as expressly provided in this Agreement.

Enurement

28. This Agreement will enure to the benefit of and be binding on the Parties and their respective heirs, executors, administrators, successors and permitted assigns.

Governing Law

31. It is the intention of the Parties to this Agreement that this Agreement and the performance under this Agreement, and all suits and special proceedings under this Agreement, be construed in accordance with and governed, to the exclusion of the law of any other forum, by the laws of the State of Idaho, without regard to the jurisdiction in which any action or special proceeding may be instituted.

Severability

32. In the event that any of the provisions of this Agreement are held to be invalid or unenforceable in whole or in part, all other provisions will nevertheless continue to be valid and enforceable with the invalid or unenforceable parts severed from the remainder of this Agreement.

Waiver

33. The waiver by either Party of a breach, default, delay or omission of any of the provisions of this Agreement by the other Party will not be construed as a waiver of any subsequent breach of the same or other provisions.

Force Majeure

34. In no event shall the Trustee be responsible or liable for any failure or delay in the performance of its obligations hereunder arising out of or caused by, directly or indirectly, forces beyond its control, including, without limitation, strikes, work stoppages, accidents, acts of war or terrorism, civil or military disturbances, nuclear or natural catastrophes or acts of God, and interruptions, loss or malfunctions of utilities, communications or computer (software and hardware) services; it being understood that the Trustee shall use reasonable efforts which are consistent with accepted practices in the banking industry to resume performance as soon as practicable under the circumstancesThe waiver by either Party of a breach, default, delay or omission of any of the provisions of this Agreement by the other Party will not be construed as a waiver of any subsequent breach of the same or other provisions